# data[].attributes.body
Contractor Obligation

Muhammad Zikri bin MD Husin
2018222663

The main Obligation of them contractor is too construct the said project which has been  agreed based on it's scope anda specification. For the contractor's general obligations, we can see in PWD.

a) Based on clause 10, contractor shall construct, completed test and commission the works in according specifications, contract drawing anda other.

b) Based on clause 39.1, the contractor shall completed the while work on or before the date of completion as state in appendix or such extender time as May be allowed in clause 43 of this document.

c) Based on clause 14 and 15 in PWD, contractor also has the obligation to be responsible with any indemnity and insurance of personal injury or death and demage to property arising from carrying out the works

d) Based on PWD clause 10(b), the contractor shall perform the work in proper manner and in accordance with good management practice and to best advantage of them government.

# data[].attributes.body
HARISAH BINTI ISMAIL

The main obligation of the contractor is to construct the said project which has been agreed based on its scope and within the specified period of time and quality. For the contractor's general obligations, it being described in PWD clause 10

Then, for the completion and sectional completion in PWD this matter is described in clause 39 and 41.

Clause 39 described on the completion of work and clause 41 described on the sectional completion

Contractor must provide performance bond to the employer as security deposit. this is a common matter required by employer to the contractor. In PWD clause 13 described on the performance bond or performance guarantee sum.

Contractor also has the obligation to ensure the quality of his works. If there is any defect during construction period and after completion, contractor has the liability to make good of any such defect until S.O satisfy with the works. This obligation is described in PWD clause 48.

# data[].attributes.headline
Contractor's Obligation According to PWD 203A 

# data[].attributes.subject
Contractor's Obligation According to PWD 203A 

# data[].attributes.body
Wan Nurul Najwa BInti Wan Zaidi

The main obligation of the contractor is to construct the said project which has been agreed based on its scope and within the specified period of time and quality. For the contractor’s general obligations, we can see in PWD clause 10.

Clause 10.0 Obligations Of The Contractor

The contractor shall :

a) construct, complete, test and commission the works in accordance with the specifications, contract drawings and any other documents specified in the contract documents.

Next, regarding works completion in PWD this matter is described in clause 39 and 41.

Clause 39.0 Completion Of Works

39.1 Subject to clauses 38.3 and 41, the contractor shall complete the whole of the works on or before the "Date for Completion" as stated in the Appendix or such extended time as may be allowed under clauses 43 hereof.

Clause 41.0 Sectional Completion

41.1 Where different completion dates for different sections or parts of the works are stated and identified in Appendix or elsewhere in the contract documents and different and separate Liquidated and Ascertained Damages are provided for each section or part of the works, the provisions of this contract regard to:

a) Certificate of Practical Completion

b) Delay and Extension of Time

c) Liquidated Ascertained Damages and

d) Defects Liability Period

Contractor also has the obligation to ensure the quality of his works. If there is any defect during construction period and after completion, contractor has the liability to make good of any such defect until S.O satisfy with the works. This obligation is described in PWD clause 48.

Clause 48.0 Defects After Completion

48.1 Completion of Outstanding Work and Remedying Defects

48.2 Default in Remedying Defects

48.3 Diminution in Value of Works

48.4 Certificate of Completion of Making Good Defects

Lastly, contractor also has the obligation to be responsible with any indemnity and insurance of personal injury or death and damage to property arising from carrying out of the Works. These matters are described in PWD clause 14 and 15. The contractor must also provide insurance for his labour as described in clause 17 of PWD.

Clause 14.0 Indemnity in Respect of Personal Injuries and Damage to Property

14.1 The contractor agrees with the government that

a) it shall perform all of its obligations under this contract at its own risk and releases, to the fullest extent permitted by law, the government and their agents and servants from all claims and demands of every kind resulting from any accident arising from the carrying out of the works except where such accident is caused to by any act of the government.

Clause 15.0 Insurance Against Personal Injuries and Damage to Propety

15.1 Taking of Insurance

15.2 Production of Policies

15.3 Default in insuring

15.4 Cancellation if Insurance

15.5 Loss or Damage Occasioned by Insured Risk

Clause 17.0 Employees' Social Security Act, 1969

17.1 Registration with SOCSO

17.2 Contribution to SOCSO

17.3 Default in Complying with SOCSO

# data[].attributes.body
MUHAMMAD FAZMI

INSURANCE

Clauses 15.1 a) and b);
In this clause it stated without prejudice to his ability to indemnify the government under clauses 14 hereof, the contractor shall, as a condition precedent to the commencement of any work under this contract, effect and maintain such insurance whether with or without an excess amount as specified in appendix to cover liability contractor and all sub-contractor whether nominated or otherwise

And also for insurance shall be for purpose personal injuries or death, damage or loss to property, movable or immovable, arising out of or in course, or by reason of the execution of the work and caused by any negligence, omission, breach of contract default contractor or sub-contractor or nominated or otherwise.

TO COMPLETE WORK

Clauses 10.0 a and c;

to complete work. Construct, complete, test and commission the work in accordance with the specification, contract drawing and any other document mush in the contract document.

The work performs much in to take all appropriate measure expected of a contractor providing similar works to ensure that the work is comply with requirement contract.

TIME

Clauses 39.1;

Subject to clause 38.3 and 42, the contractor shall complete the whole work on or before the ‘date for completion’ as stated in the appendix or such extended time as may be allowed under clause 43 of this document

DESIGN

Clauses 48.1 a);

Time during defect of liability period as stated in appendix hereto ( or if none stated the period is twelve month from the date of practical completion  of the work), any defect, imperfection, shrinkage or any other fault what ever which may appear and which are due to materials or goods  or workmanship not in accordance with this contract, the S.O shall issue written instruction to the contractor to make good such defect, imperfections, shrinkages or any other fault at the contractor own cost. Should complete work in die of expedition or within such time as may be specified by S.O.

# data[].attributes.body
The main obligation of the contractor is to construct the said project which has been agreed based on its scope(clause 10.a) and within the specified period of time(clause 39.1) and quality(clause 36). In P.W.D clause 10.a, that explain main obligation stated the contractor shall construct, complete, test, and commission the works in accordance with the specification, contract Drawing and any other documents specified in the Contract Documents.
Next, contractor must provide performance bond to the employer as security deposit. This is a common matter required by employer to the contractor for the site posesion as stated in clause 13 for the performance bond and and clause 38 for the site possesion. Contractor also has the obligation to ensure the quality of his works. If there is any defect during construction period and after completion, contractor has the liability to make good of any such defect until S.O satisfy with the works as stated in the clause 48.1. Fourth, regarding the works completion. Contractor need to complete the project within the specified time as stated in clause 39, Completion of Works.

Firas Najmi

# data[].attributes.body
Contractors are the one who contracts to carry out and complete construction works in return for a financial consideration. The contractor is responsible for the planning of the work and for the acquisition and deployment and resources on site to achieve the completion of the project.

Implied obligation includes time, workmanship, materials, design and obligations to complete work.

The main obligation
of the contractor is to construct the said project which has been agreed based
on its scope and within the specified period of time and quality.

Based on standard
form of contract PWD 203A, there are several contractor's obligations stated.

Clause 10 described about contractor’s obligations generally.  For example in clause 10a stated that - The contractor shall construct, complete, test and commission the Works in accordance with the Specifications, Contract Drawings and any other documents specified in the Contract Documents;

Next, completion and sectional completion are described in clauses 39 and 41.

Clause 39 stated that the contractor shall complete the whole of the works on or before the "Date for Completion" as stated in the appendix or such extended time as may be allowed under clause 43 hereof.

Meanwhile Clause 41 is about sectional completion where different completion dates for different sections or parts of the works are stated in the appendix or in the contract document itself. The contractor must provide performance bond to the employer as security deposit. The performance bond shall be released or be refunded only when the Certificate of Making Good defects of the whole works has been issued.

Lastly, the contractor obligation on defects after completion explained in clause 48. The contractor has to ensure that the quality of his work is good. Contractor has the liability to make good of any such defect until S.O. is satisfied with the works if there is any defect during construction period and after completion.

SITI NUR FIRDA AZEERA BT MOHD FIKRI

# data[].attributes.headline
Four contractor obligations based on standard form of contract PWD 203A- nurul hasanah johari

# data[].attributes.subject
Four contractor obligations based on standard form of contract PWD 203A- nurul hasanah johari

# data[].attributes.body
1. The contractor has the obligation to ensure the quality of his works. If there is any defect during construction period and after completion, contractor has the liability to make good of any such defect until S.O satisfy with the works. This obligation is described in PWD clause 48
2. ‎Contractor also has the obligation to be responsible with any indemnity and insurance of personal injury or death and damage to property arising from carrying out the works. These matters are described in PWD clause 14 and 15. The constractor must also provide insurance for his labour as described in clause 17 of PWD
3. ‎Theres is also specific clause regarding to antiquities such as fossils, coins etc which may be found on the site. In this circumstance, contractor has the obligation to take all steps which may be necessary to preserve and protect the object in the exact position and condition. The contractor should inform S.O immediately about the discovery. This obligation can be seen in clause 64 of PWD
4. ‎S.O can appoint nominated sub contractor (NSC) or nominated supplier (NS) with the approval from the contractor. And again, contractor shall be fully responsible for the works of NSC/NS. These matters are described in PWD clause 47 and 59

# data[].attributes.headline
Contractor's Obligation According to PWD 203A

# data[].attributes.subject
Contractor's Obligation According to PWD 203A

# data[].attributes.body
1.     Carry out construction works

Based on PWD Clause 10(a), the contractor should construct and complete the works in accordance with specifications, contract drawings and any other documents

2.       Provide and organize resources for the constructed project in accordance with the design, within time and cost parameters

According to PWD Clause 10(b), the contractor shall perform the work in proper manner and in accordance with good management practice and to best advantage of the government.

3.    Contractor has obligation to ensure the quality of his work. If any defect during construction period and after completion, contractor liable to make good of any defect until S.O satisfy with the works.

Based on PWD Clause 10(j), contractor should make good any defect, imperfection, shrinkage or any other fault which may appear during the Defect Liability Period(DLP).

4.      Contractor has obligation by responsible with any indemnity and insurance of personal injury or death and damage to the property arising from carrying out of the works. These matters are described in PWD Clause 14 and 15. Then, contractor should provide insurance to his labour as described in PWD Clause 17.

-Muhammad Hariz bin Hasan

# data[].attributes.headline
Contractor's Obligations According to PWD 203A

# data[].attributes.subject
Contractor's Obligations According to PWD 203A

# data[].attributes.body
Contractor is the person who contracts to carry out and complete construction works in return for a financial consideration.

First obligation of the contractor is to construct the project which has been agreed based on its scope and within the specified period of time and quality. Based on form of contract PWD 203A, 10.0 (a) the contractor shall construct, complete, test and commission the works in accordance with the specifications, contract drawings and any other documents specified in the contract documents.

Second obligation of the contractor is to ensure the quality of his works. If any defect during construction period and after completion, contractor has the liability to make good of any such until the S.O satisfy with the works. Based on form of contract PWD 203A, 48.1 (a) any defect, imperfection, shrinkage or any other fault, whatsoever which may appear and which are due to materials or goods or workmanship not in accordance with the contract, the S.O shall issue written instruction to the contractor to make good such defects, imperfections, shrinkages or any other fault whatsoever at the contractor’s own cost. The contractor also shall complete all works within the time as specified by S.O.

Next obligation of contractor is in testing and inspection. S.O needs to take a test of the work done by contractor and usually the cost of testing and inspection are borne by contractor. Based on form of contract PWD 203A, 36.6 if the contractor carries out any further test as required by the S.O and the result of the test shows the workmanship or materials is not in accordance with the provision of contract, the cost of the test will be borne by the contractor. However, if the result of the test shows the workmanship and materials comply with the provision of contract, the test will be borne by the government.

Last obligation of contractor is to be responsible with any indemnity and insurance of personal injury or death and any damage to property that caused by the carrying out of works. Based on form of contract PWD 203A, 14.1 (a) the contractor agrees with the government that it shall perform all of its obligations under the contract at its own risk and releases to the fullest extent permitted by law, the government and their agents and servants from all claims and demands of every kind resulting from the carrying out of works except the injuries and damages caused by any act or negligence of the government or agents and servants.

Nurul lzzah binti Rahim

# data[].attributes.headline
Contractor's Obligations According to PWD 203A

# data[].attributes.subject
Contractor's Obligations According to PWD 203A

# data[].attributes.body
1.       Carry out construction works

Based on PWD Clause 10(a), the contractor should construct and complete the works in accordance with specifications, contract drawings and any other documents

2.     Provide and organize resources for the constructed project in accordance with the design, within time and cost parameters

According to PWD Clause 10(b), the contractor shall perform the work in proper manner and in accordance with good management practice and to best advantage of the government.

3.

# data[].attributes.headline
4 contractor obligation based on PWD 203A

# data[].attributes.subject
4 contractor obligation based on PWD 203A

# data[].attributes.body
Based on PWD 203A, contractor is a person or organisation that are carry out the construction works. Contractor is a person that provide and organize resources for constructed the project accordance the design within the time and cost.

Accordance to the obligation of contractor in PWD 203A,

In the clause 39 and 41 has been describe that the main obligation of the contractor is to construct the project which has been agreed based on its scope and within the specified period of time and quality.

Furthermore, contractor also has the obligation to be responsible with any indemnity and insurance of personal injury or death and damage to property arising from carrying out of the Works. These matters are described in PWD clause 14 and 15.

Next, the contractor has the obligation to ensure the quality of his works. Contractor has the liability to make good of any such defect until S.O satisfy with the works if there have any defect during the defect liability period. This obligation is described in PWD clause 48.

In the clause 47 describe that the contractor also has the obligation to execute the whole Works. If he would like to assign some duties to his subcontractors, first he must receive the approval of S.O. If S.O approves his assignment, the contractor shall still be fully responsible for the works of his subcontractors.

Moreover,  Clause 65 in PWD 203A is describe specific regarding to antiquities such as fossils, coins that may be found on the site during excavating. In this circumstance, contractor has the obligation to take all steps that may be necessary to preserve and protect the object in the exact position and condition. The contractor should inform S.O immediately about the discovery and precise the location of the object.

Arfah Hazirah Bt Sobli

# data[].attributes.headline
Four Contractor Obligation based on PWD 203A

# data[].attributes.subject
Four Contractor Obligation based on PWD 203A

# data[].attributes.body
A contractor is a person hired by the client to carry out the work that is required for a completion of a project.

Firstly, the contractor obligation is completion and sectional completion. In PWD 203A, the contractor obligation is described in clause 39 and 41.  In clause
39.1 described as subject to clauses 38.3 (Date of Completion) and clause 41 (Sectional Completion), the contractor shall complete the whole of the works on or before the “Date of Completion” as stated in the Appendix or such extended
time as may be allowed under clause 43 (Delay and Extension of Time) hereof.

Secondly is contractor obligation is on testing and inspection. S.O sometimes needs to take a test of the works done by the contractor. Usually the cost of the inspection and testing are borne by the contractor. This matter is described in PWD 203A in clause 36 which is inspection and testing of materials, goods and equipment. In clause 36.1 stated that the contractor shall submit to the S.O for his approval, proposals for inspecting the design and setting out the works and testing the materials and workmanship to ensure that the contractor’s obligation is under the contract is fulfilled.

Next, in clause 10 (i) is about subcontractor. The contractor also has the obligation to execute the whole works. If he would like to assign some duties to his subcontractors, he must receive the approval of S.O first. If S.O approves his assignment, the
contractor shall still be fully responsible for the works of his
subcontractors. In clause 10 (i) stated that contractor shall instruct and supervise its staff and sub-contractor in carrying out the works' repair and other works in the relation to the works.

Lastly, in PWD 203A clause 10 (j) and clause 48 is about defect.  Contractor also has the obligation to ensure the quality of his work. If there any defect during construction period and after completion, contractor has the liability to make good of any such defect until S.O satisfy with the work. In PWD 203A in clause 10 (J) contractor shall make good
any defect, imperfection, shrinkage or any other fault whatsoever which may appear during the Defect Liability Period.

-Nur Hazwani Bt
Mohd Ibrahim-

# data[].attributes.headline
contractor obligations based on standard form of contract PWD 203A

# data[].attributes.subject
contractor obligations based on standard form of contract PWD 203A

# data[].attributes.body
nurul alya bt sa'ari

contractor is the one who contracts to carry out and complete construction works in return for a financial consideration. based on PWD 203A, there are several contractor's obligations stated.

Based on PWD 203A, the first one is to construct the said project that has been agreed in according with specified period of time and quality.

next, the contractor has the obligation to ensure the qualoty of his works. Contractor has the liability to make good of any such defect until S.O satisfy with the works if there have any defect during the defect liability period, this obligation is explained in PWD clause 48.

the contractor shall take all appropriate measures expected of a contractor providing similar works to ensure that the works comply with the requirements of the contract, based on clause 10h, the contractor shall provide and maintain at its own cost and expense all equipment and materials necessary for the proper and effective performance of the works.

Lastly, based on clause 10j, make good any defect, imperfection, shrinkage or any other fault whatsoever which may appear during the Defect Liability Period. this clause explain that any defect that occurs to the building during the Defect liability Period (DLP), the contractor is liable to repair any defect of the building. this can be refer to clause 48 in the P.W.D.

# data[].attributes.body
h
Avatar of anonymous
Anonymous
1m
h
Your avatar
Add comment
ni-
Avatar of anonymous
Anonymous
1m
ni-
Your avatar
Add comment
ompletion of work has des
Avatar of anonymous
Anonymous
1m
ompletion of work has describe in PWD in clause 39 and 41,completion and sectional completion.
Your avatar
Add comment
Contractor's obligation according to PWD 203A
Avatar of anonymous
Anonymous
1m
Contractor's obligation according to PWD 203A
1. Carry out construction works
=>According to PWD in Clause 10(a), the contractor should construct, complete, test and commission of the Works according to the Specifications, Contract Drawings and any related documents specified in Contract Documents.

2. Provide and organize resources for the constructed project in accordance with the design, within time and cost parameters.
=>Based on PWD Clause 10(b), the contractor shall perform the Work in a proper manner and in accordance with good management practice and to the best advantage of the Government

3. Contractor has obligation to ensure the quality of the works. If any defect happened during construction period and after completion, contractor liable to make good of any defect until S.O satisfy with the works.
=>According to PWD Clause 10, the contractor should make good any defect, imperfection, shrinkage or any fault which may appear during the Defect Liability Period.

4.
Your avatar
Add comment
4 contractor obligations based on standard form of contract PWD 203A
Avatar of anonymous
Anonymous
1m
4 contractor obligations based on standard form of contract PWD 203A
Contractor is the one who contracts to carry out and complete construction works in return for a financial consideration. Based on PWD 203A, there are few contractor obligations stated. 
Firstly, in clause 10.a, the contractor shall construct, complete, test and commission the work accordance to the specification, contract drawings and contract documents within specified period of time and quality.
Secondly,  in clause 48 is stated about defects after completion. Thus, the contractor has to make sure their quality of work is good. If there is any defect, the contractor has liability to complete the works within time specified by S.O..
 Third, 
Your avatar
Add comment
CONTRACTOR'S OBLIGATIONS BASED ON PWD 203A
Avatar of anonymous
Anonymous
1m
CONTRACTOR'S OBLIGATIONS BASED ON PWD 203A

 According to the PWD 203A, the obligations of the contractors are :

Firstly, clause 10(a) states that the contractor shall construct, complete,  test and commission the Works in the Specifications, Contract Drawings and any other documents specified in the Contract Documents.

2) Clause 10(b) states that contractor shall perform the Works in a proper manner and in accordance with good management practice and to the best advantage of the Government.

3) Contractor shall provide and maintain throughout the Contractor Period such number, categories of qualified and competent personnel necessary to perform the Works.

4) The contractor shall instruct and supervise its staffs and sub-contractor in carrying out the Works' repairs and other during the Defects Liability Period. 


Your avatar
Add comment
Atiq Syafira
Avatar of anonymous
Anonymous
1m
Atiq Syafira                                 


- The contractor is one who   contracts to carry out and complete construction works in return  for financial consideration.

- Four contractor obligation;
  a) Defect
     - Contractor has the obligation
       ensure the quality of his work. 
     - If there is any defect during 
       construction period and after 
       completion, contractor has the
       liability to make good of any 
      such defect until S.O. satisfy 
      with the works 
      (PWD clause 48).

     b) Completion and sectional   
          completion
     - Contractor must provide 
        performance bond to the 
        employer as security deposit.
     - When the whole of the works 
       have reached practical 
       completion to the satisfaction
       of
       the S.O., the date of such completion shall be certified by him and such date shall be
       the date of the commencement of the Defect Liability as provided in clause 48 hereof
       ( Clause 39.6)

Your avatar
Add comment
Four contractor obligations based on standard form of contract PWD 203A *
Avatar of anonymous
Anonymous
1m

# data[].attributes.headline
describe four contractor obligations based on standard form of contract PWD 203A 

# data[].attributes.subject
describe four contractor obligations based on standard form of contract PWD 203A 

# data[].attributes.body
Firstly, the main obligation of the contractor is to construct the said project which has been agreed based on its scope and within the specified period of time and quality. This can see in PWD clauses 10.
Besides, the other obligation is to complete because sometimes the employer wants to take some part of the Works which are already completed. This described in clauses 39 and 41.
Next, contractor must provide performance bond to the employer as security deposit. This is a common matter required by employer to the contractor.
Lastly, contractor also has the obligation to ensure the quality of his works. If there is any defect during construction period and after completion, contractor has liability to make good of any such defect until S.O satisfy with the works. This obligation is described in PWD clauses 48.

Shafatin Adni Bt Shukri
2018298878

# data[].attributes.body
ompletion of work has describe in PWD in clause 39 and 41,completion and sectional completion.

# data[].attributes.headline
Contractor's obligation according to PWD 203A

# data[].attributes.subject
Contractor's obligation according to PWD 203A

# data[].attributes.body
1. Carry out construction works
=>According to PWD in Clause 10(a), the contractor should construct, complete, test and commission of the Works according to the Specifications, Contract Drawings and any related documents specified in Contract Documents.

2. Provide and organize resources for the constructed project in accordance with the design, within time and cost parameters.
=>Based on PWD Clause 10(b), the contractor shall perform the Work in a proper manner and in accordance with good management practice and to the best advantage of the Government

3. Contractor has obligation to ensure the quality of the works. If any defect happened during construction period and after completion, contractor liable to make good of any defect until S.O satisfy with the works.
=>According to PWD Clause 10, the contractor should make good any defect, imperfection, shrinkage or any fault which may appear during the Defect Liability Period.

4. Workmanship
=>Based on PWD Clause 10(d), the contractor should perform the Works and discharge its obligation as stated in Contract, by exercising professional practice and judgement, requisite skill, care and diligence. When performing works, the contractor need to provide well-outlined procedures in the form agreed by the Goverment

# data[].attributes.headline
4 CONTRACTOR'S OBLIGATIONS BASED ON PWD 203A

# data[].attributes.subject
4 CONTRACTOR'S OBLIGATIONS BASED ON PWD 203A

# data[].attributes.body
According to the PWD 203A, the obligations of the contractors are :

1. TO CONSTRUCT WORK
The contractor shall construct, complete,  test and commission the Works in the Specifications, Contract Drawings and any other documents specified in the Contract Documents.
(Clauses 10a)

2. COMPLETION AND SECTIONAL COMPLETION
Based on the PWD 203A,  the Contractor shall complete the whole of the Works on or before the "Date for Completion" as stated in the Appendix or such extended time as may be allowed under clause 43 hereof.  The contractor shall inform the S.O in writing to that effect if the contractor considers that the works achieved practical completion.
(Clauses 39.1 &  Clause 39.2)

3. DEFECTS AFTER COMPLETION
According to PWD 203A,  the S.O shall issue written instruction to the Contractor to make good such defects, imperfections, shrinkage or any other fault whatsoever at the Contractor's own cost at any time during the Defects Liability Period. The contractor shall complete all such works with due expedition or within such time as may be specified by the S.O.
(Clause 48.1)

4) INSURANCE
Such insurance shall be for the purpose of personal injuries or death, damage or loss to property, movable or immovable, arising out of, or in the course of, or by reason of the execution of the Works and caused by any negligence, omission, breach of contract or default of the Contractor or any sub contractor, whether nominated or otherwise, or of any servants or agents of the Contractor or of any such sub-contractor, whether nominated or otherwise. The contractor shall bear the amount of such excess, where a excess amount is specified in Appendix.  The policy or policies of insurance shall contain a cross liability clause indemnifying each of the jointly insured against claims made by on him by other jointly insured. ( Clause 15.1b)

NURUL AFIQAH BT ZAMBARI

# data[].attributes.headline
4 contractor obligations based on standard form of contract PWD 203A

# data[].attributes.subject
4 contractor obligations based on standard form of contract PWD 203A

# data[].attributes.body
-NUR HAFIZAH BINTI AHMAD @ MUHD ZAILANI-

Contractor is the one who contracts to carry out and complete construction works in return for a financial consideration. Based on PWD 203A, there are few contractor obligations stated.
Firstly, in clause 10.a, the contractor shall construct, complete, test and commission the work accordance to the specification, contract drawings and contract documents within specified period of time and quality.
Secondly,  in clause 48 is stated about defects after completion. Thus, the contractor has to make sure their quality of work is good. If there is any defect, the contractor has liability to complete the works within time specified by S.O..
Third, completion  and sectional completion in clause 39 and clause 41. According to clause 39.1, the contractor shall complete all the works on or before the Date of Completion as in the contract. in clause 41, stated that some parts of works has different completion dates.
Lastly, in clause 13 stated that the contractor shall provide a Performance Bond or Performance Guarantee Sum to the employer as security deposit.

-NUR HAFIZAH BINTI AHMAD @ MUHD ZAILANI-

# data[].attributes.headline
Atiq Syafira                                 

# data[].attributes.subject
Atiq Syafira                                 

# data[].attributes.body
- The contractor is one who   contracts to carry out and complete construction works in return  for financial consideration.

- Four contractor obligation;
a) Defect
- Contractor has the obligation
ensure the quality of his work.
- If there is any defect during
construction period and after
completion, contractor has the
liability to make good of any
such defect until S.O. satisfy
with the works
(PWD clause 48).

b) Completion and sectional
completion
- Contractor must provide
performance bond to the
employer as security deposit.
- When the whole of the works
have reached practical
completion to the satisfaction
of the S.O., the date of such
completion shall be certified
by him and such date shall be
the date of the
commencement of the Defect
Liability as provided in clause
48  ( Clause 39.6)
c) Design liability
- The contractor shall submit to
the S.O. all drawings,
specifications, calculations
and any other relevant
information pertaining to the
stand alone design for
approval. No work shall
commence without prior
written consent of the S.O.
(Clause 22.1(b))

d) Materials
- Clause 35.1 stated that all
materials, goods and
workmanship shall be of the
respective kinds and standards
described in the specification
and of good quality and in
accordance with the standard
workmanship in the industry.
- The contractor shall upon the
request of the S.O furnish
him with relevant
certificates and/or voucher
to prove that  the materials and
goods comply with the
specification.

# data[].attributes.headline
Four contractor obligations based on standard form of contract PWD 203A *

# data[].attributes.subject
Four contractor obligations based on standard form of contract PWD 203A *

# data[].attributes.body
The main obligation of the contractor is to construct the said project which has been agreed based on its scope and within the specified period of time and quality, as we can see in PWD clause 10.

The contractor also need to complete their work base on the contract  as describe in PWD in clause 39 and 41 about completion and sectional completion.

The contractor must provide performance bond to the employer as security deposit. This is a common matter required by employer to the contractor as stated in PWD clause 13.

Contractor also has the obligation to ensure the quality of his works. If there is any defect during construction period and after completion, contractor has the liability to make good of any such defect until S.O satisfy with the works. This obligation stated  in PWD clause 48.

Muhamad Syakir Iman Bin Muhamad Suhaimi

# data[].attributes.headline
 4 contractor obligations based on standard form of contract PWD 203A

# data[].attributes.subject
 4 contractor obligations based on standard form of contract PWD 203A

# data[].attributes.body
Clause 10 explains 11 general obligations of the contractor from clause 10a to clause 10k. One of the clauses state that:
The Contractor shall
construct,complete, test and commission the Works in accordance with the specifications, contract drawings and any other documents specified in the contract document.This clause explains the main obligation of the contractor which is to construct and complete the project which has been agreed based on its scope and within the specified period of time and quality in the contract document.

Clause 39 is regarding the contractor obligations during completion of works. The contractor shall complete the whole of the works on or before 'the date of completion' as stated/agreed in the appendix of contract document or such extended time as may be allowed under clause 43 (Delay and EOT). If the contractor considers that the work have achieved practical completion, the contractor shall notify the S.O. in writing. Within 14 days of the notice receipt, the S.O. shall carry out testing/ inspection of works before issuing Certificate of Practical Completion.

Clause 41 is about sectional completion where different completion dates for different sections or parts of the works are stated in the appendix or in the contract document itself. The contractor must provide performance bond to the employer as security deposit. The performance bond shall be released or be refunded only when the Certificate of Making Good defects of the whole works has been issued.

Lastly, in clause 48 explained the contractor obligation on defects after completion. The contractor has to ensure the quality of his works. If there is any defect during construction period and after completion, contractor has the liability to make good of any such defect until S.O. satisfied with the works.

I'ZZAH LIYANA BT MOHAMAD ROSLI

# data[].attributes.headline
Obligation of Contractor based on PWD 203A

# data[].attributes.subject
Obligation of Contractor based on PWD 203A

# data[].attributes.body
Contractor is the one who contracts to carry out and complete construction works in return for a financial consideration. Based on PWD 203A, there are several contractor's obligations stated.

The first one is to construct the said project that has been agreed  in according with the specified period of time and quality.

Secondly,  providing the performance bond to the employer as security deposit. This is common matter that the employer required from contractor

Next, the obligation of contractor in making sure their quality of works. Contractors have liability in making good such any defect if there is  any defect in construction period until they achieved the satisfaction of S.O. This is stated in clause 48 of PWD.

Lastly, clause 39 and 41 of PWD mentioned about completion and sectional completion. Based on clause 39 in PWD which subject to clause 38.3 and 41, the contractor shall complete their works on or before the date of completion as stated in the Appendix or clause 43 also allowed such extended time.

-Aqila Natasha-

# data[].attributes.body
contractor is a organisation or sometimes a person, hired by the client to carry out the work that is required for the completion of a project. Contractor also have different levels such they are responsible for a wide range of tasks and people. Based on PWD 203A, there are a few obligations stated for the contractor.

1.      A contractor shall construct the project according to the terms agreed  and based on its scope within the specified time and quality. Clause 10 stated that contractor shall construct, complete, test and commission the works in accordance with the specifications. Contract drawing and any other documents specified in the contracts documents.

2.      Clause 48 stated that the contractor has the obligation to ensure the quality of his work. If there is any defect during the construction period and after completion, contractor has the liability to make good of any such defect until S.O  satisfied with the works. The contractor shall complete all such works with due expidition or within such time as may be specified by the S.O.

3.      Clause 10(g) state that the contractor shall provide and maintain throughout the contract period such number, categorised of qualified and compenent personnel necessary to perform the works

4.       The contractor also shall complete the whole of the works on or before the ‘date for completion’ as stated in clause 39.1 and if the contractor considers that the works have achieved practical completion, the contractor shall notify the S.O in writing to that effect.

-Nor Aisyah-

# data[].attributes.body
https://docs.google.com/forms/d/e/1FAIpQLScEFY3kh7HPcQGCfdyCjA7voFMCIvwpzH-6jV4nbJJOUEOxKw/viewform?usp=sf_link

# data[].attributes.body
https://drive.google.com/file/d/1MpUg_d9oGivY4f6FcFoHNPRh8iAAVVpi/view?usp=sharing

# data[].attributes.headline
RAJA NAJWA NAJEEHA BT RAJA SHAMIL YAHIDIN 

# data[].attributes.subject
RAJA NAJWA NAJEEHA BT RAJA SHAMIL YAHIDIN 

# data[].attributes.body
Based on the  standard form of contract P.W.D. 203A under section 10.0 (OBLIGATIONS OF THE CONTRACTOR) ;

The Contractor shall :-

10. A -
construct, complete, test and commission the Works in accordance with the Specifications, Contract Drawings and any other documents specified in the Contract Documents;

In this clause, it explain that the contract is responsible to construct the building until completion ( hand-over phase) and the detail of the building shall follow the Specifications based on the contract document as it has already being agreed by both parties. This clause is explaining the general obligation of the contractor.

10. J-
make good any defect, imperfection, shrinkage or any other fault whatsoever which may appear during the Defect Liability Period;

This clause is explaining that any defect that occurs to the building during the Defect Liability Period (DLP) , the Contractor is liable to repair any defect of the building. This can be refer to clause 48 in the P.W.D , stated that the DLP is at anytime as stated in the appendix. If the period of DLP is not mentioned thus, the period will be 12 months from the date of practical completion of work. It includes any defect, imperfection, shrinkage, or any other fault.

Based on the  standard form of contract P.W.D. 203A under section 39 ( COMPLETION OF WORK)

Clause 39.1

Subject to clauses 38.3 and 41, the contractor shall complete the whole Works on or before the "Date for Completion" as stated in the Appendix or such extended time as may be allowed under clause 43 hereof.

Clause 39.2

If the Contractor considers that the work have achieved practical completion, the Contractor shall notify the S.O. in writing to the effect.

This clauses is explaining that the Contractor need to complete the construction during or before the Date of Completion. This is to avoid the Extension of Time or Liquidated Ascertain Damages happen. In related to clause 41 of SECTIONAL COMPLETION, different type of completion date for different sections or parts of the Works shall be stated and mentioned in the Appendix or in the Contract Documents.

Based on the  standard form of contract P.W.D. 203A under section 13 (PERFORMANCE BOND/PERFORMANCE GUARANTEE SUM);

The Contractor shall provide a Performance Bond as it might be a substantial in the form as in the  Appendix by the approved licensed bank or financial institution incorporated in Malaysia in favor of the Government for a sum equivalent to five percent of the total contract sum. The performance bond shall remain valid and effective until 12 months after the expiry of the DLP or the issuance of the Certificate of Completion of Making Good Defects.

# data[].attributes.body
The main obligation of the contractor is to
construct the said project which has been
agreed based on its scope and within the
specified period of time and quality.For the contractor’s general obligations, we
can see in PWD clause 10.
Contractor also need to complete their works base on the contract.completion of work has describe in PWD in clause 39 and 41,completion and sectional completion.
Contractor also must provide performance bond to the employer as security deposit.this is common matter required by the employer to the contractor. we can find the clause about performance bond in clause 13.
Contractor also has the obligation to ensure the quality of his works. If there is any defect during construction period and after
completion, contractor has the liability to make good of any such defect until S.O satisfy with the works. This obligation is described in PWD clause 48

'AZMANAZMI